Construction contract template

This a construction contract template sample that you can use free of charge. You can copy and paste it into Microsoft Word or Google Docs and edit as you like.

Construction Service Agreement

This Construction Service Agreement (the "Contract") is entered into on _________________________ [Date] by and between:

Construction service provider: _________________________ [Contractor or Company Name] located at _________________________ [Provider Address] (the "Provider").
Client: _________________________ [Client Name] located at _________________________ [Client Address] (the "Client").

1. Scope of Services

The Provider agrees to provide construction services to the Client as outlined below:

1. Service Description

The Provider shall perform construction work at the Client's premises located at _________________________ [Project Address] starting on _________________________ [Start Date] and continuing until _________________________ [Estimated Completion Date].

2. Services Included

The construction services shall include but are not limited to:

_________________________ [Site preparation and excavation]
_________________________ [Foundation laying and structural framing]
_________________________ [Roofing, siding, and exterior finishes]
_________________________ [Interior finishes including flooring, painting, and fixtures]
_________________________ [Electrical, plumbing, and HVAC installation]
_________________________ [Inspection coordination and compliance with local codes]
_________________________ [Other construction tasks as agreed upon by both parties]

3. Project Schedule

The Provider shall provide a project schedule outlining key milestones, deadlines, and completion dates. Updates to the schedule shall be communicated in writing if delays or changes occur.

2. Terms of Contract

This Contract shall commence on _________________________ [Start Date] and remain in effect until the project is completed, unless terminated earlier as provided herein.
Any modifications to the project scope, materials, or timeline must be agreed upon in writing by both parties.

3. Payment Terms

The Client agrees to pay the Provider a total sum of $_________________________ [Amount] for the construction project.
Payments shall be made in installments based on project milestones as follows: _________________________ [Milestone Payment Schedule].
Final payment shall be due upon substantial completion of the project and after the Client’s inspection and approval.
Late payments shall incur a late fee of _________________________ [Late Fee Amount] per _________________________ [Week/Month] overdue.

4. Termination

Either party may terminate this Contract by providing written notice to the other party _________________________ [Number] days prior to the intended termination date.
In the event of termination, the Client shall pay for all completed work, materials purchased, and reasonable costs incurred up to the termination date.

5. Force Majeure

Neither party shall be liable for any failure or delay in performing their obligations under this Contract due to circumstances beyond their reasonable control, including but not limited to acts of God, natural disasters, strikes, or government restrictions.

6. Confidentiality

Both parties agree to maintain the confidentiality of any proprietary or sensitive project information disclosed during the course of this Contract.

7. Governing Law and Jurisdiction

This Contract shall be governed by and construed in accordance with the laws of _________________________ [Your State or Country]. Any disputes arising out of or in connection with this Contract shall be resolved exclusively by the courts of _________________________ [Your State or County].

8. Entire Agreement

This Contract constitutes the entire agreement between the parties and supersedes all prior agreements, discussions, and negotiations, whether written or oral.

IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.

Provider
Signature: _________________________ [Signature]
Name and title: _________________________ [Name and Title]
Date: _________________________ [Date]

Client
Signature: _________________________ [Signature]
Name and title: _________________________ [Name]
Date: _________________________ [Date]

Sign documents for free

No signup required

What's a Construction Contract?

A construction contract is a legally binding agreement between a property owner (or client) and a contractor, outlining the terms, responsibilities, and obligations for a construction project. This contract ensures that both parties understand the project's scope, cost, timeline, and quality expectations. In this article, we'll break down the essential components of a construction contract, its significance, and what to consider when drafting or signing one.

1. Definition and Scope

A construction contract defines the scope of work to be performed, including design, building, renovation, or repair tasks. It typically specifies project plans, blueprints, materials, and labor required, as well as any special provisions like subcontractor involvement or site preparation. The scope should be as detailed as possible to prevent misunderstandings.

2. Parties Involved

The contract identifies the key parties involved:

Client/Owner: The individual or entity commissioning the project.
Contractor: The individual or company responsible for carrying out the construction work.
It may also mention architects, engineers, and subcontractors, along with their roles and contact information.

3. Terms and Conditions

Construction contracts outline the legal terms governing the project, including pricing, payment schedule (milestones, deposits, final payment), warranties, and penalties for delays. They also address change orders, indemnity clauses, liability, and procedures for handling disputes or breaches.

4. Duration and Deadlines

Time is a critical factor in construction. The contract specifies the start date, project timeline, and estimated completion date. It may also include milestone deadlines, extension conditions, and penalties or bonuses for early or late completion.

5. Specifications and Quality Standards

The agreement details materials to be used, construction techniques, and quality standards that must be met. This section ensures that the final build meets the agreed-upon design and complies with industry standards and codes.

6. Legal Compliance

Construction contracts must comply with building codes, zoning laws, safety regulations, and labor laws. This section may also include requirements for permits, inspections, and insurance coverage to protect both parties against legal and financial risks.

7. Risk Management and Warranties

Risk allocation is a crucial element. The contract should clarify which party bears responsibility for accidents, property damage, or unforeseen circumstances (e.g., weather delays). Warranties on workmanship and materials are often included to guarantee quality after completion.

Conclusion

Construction contracts are essential tools for ensuring that projects are completed on time, within budget, and to the agreed quality standards. They provide legal protection for both clients and contractors, reduce the likelihood of disputes, and clearly define expectations. Whether you are commissioning or providing construction services, understanding the key components of a construction contract is critical to achieving a smooth, successful project outcome.