Roofing contract template

This a roofing contract template sample that you can use free of charge. You can copy and paste it into Microsoft Word or Google Docs and edit as you like.

Roofing Service Agreement

This Roofing Service Agreement (the "Contract") is entered into on ________________________ [Date] by and between:

Roofing service provider: ________________________ [Roofer or Company Name] located at ________________________ [Roofer Address] (the "Provider").
Client: ________________________ [Client Name] located at ________________________ [Client Address] (the "Client").

1. Scope of Services

The Provider agrees to provide roofing services to the Client as outlined below:

1. Service Description

The Provider shall perform roofing services at the Client's premises located at ________________________ [Service Address] on ________________________ [Days of the Week], between the hours of ________________________ [Start Time] and ________________________ [End Time].

2. Services Included

The roofing services shall include but are not limited to:

________________________ [Roof inspection and assessment]
________________________ [Roof repair and maintenance]
________________________ [Roof replacement or installation]
________________________ [Gutter cleaning and repair]
________________________ [Leak detection and waterproofing]
________________________ [Debris removal and site cleanup]
________________________ [Other roofing tasks as agreed upon by both parties]

3. Frequency

The services shall be performed ________________________ [Frequency] per ________________________ [Week/Month].

2. Terms of Contract

This Contract shall commence on ________________________ [Start Date] and shall continue for an initial term of ________________________ [Number] months/years, unless terminated earlier as provided herein.
After the initial term, this Contract shall automatically renew for successive periods of ________________________ [Number] months/years, unless either party provides written notice of termination at least ________________________ [Number] days prior to the expiration of the then-current term.

3. Payment Terms

The Client agrees to pay the Provider a total sum of $________________________ [Amount] per ________________________ [Frequency] for the roofing services rendered.
Payment shall be made ________________________ [Payment Method] within ________________________ [Number] days of receipt of invoice.
Late payments shall incur a late fee of ________________________ [Late Fee Amount] for each week the payment is overdue.

4. Termination

Either party may terminate this Contract by providing written notice to the other party ________________________ [Number] days prior to the intended termination date.
In the event of termination, the Client shall pay for all services rendered up to the termination date.

5. Force Majeure

Neither party shall be liable for any failure or delay in performing their obligations under this Contract if such failure or delay is due to circumstances beyond their reasonable control, including but not limited to acts of God, war, terrorism, civil unrest, government action, fire, flood, or natural disasters.

6. Confidentiality

Both parties agree to maintain the confidentiality of any proprietary or sensitive information disclosed during the course of this Contract.

7. Governing Law and Jurisdiction

This Contract shall be governed by and construed in accordance with the laws of ________________________ [Your State or Country]. Any disputes arising out of or in connection with this Contract shall be resolved exclusively by the courts of ________________________ [Your State or County].

8. Entire Agreement

This Contract constitutes the entire agreement between the parties and supersedes all prior agreements, understandings, and negotiations, whether written or oral.

IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.

Provider
Signature: ________________________ [Signature]
Name and title: ________________________ [Name and Title]
Date: ________________________ [Date]

Client
Signature: ________________________ [Signature]
Name and title: ________________________ [Name]
Date: ________________________ [Date]

Sign documents for free

No signup required

What's a Roofing Contract?

A roofing contract is a legally binding agreement between a property owner (the client) and a roofing contractor or company (the provider) that clearly outlines the terms, conditions, and scope of roofing services to be performed. This contract helps ensure both parties understand their roles, responsibilities, and expectations before any work begins. In this article, we'll explore the essential elements of a roofing contract, its importance, and key factors to consider when drafting or entering into one.

1. Definition and Scope

A roofing contract defines the scope of roofing services, specifying whether the job involves inspection, repairs, replacements, or full installation. It details the exact tasks to be performed, such as removing old roofing materials, installing new shingles or tiles, sealing leaks, or performing maintenance work. It also includes start and completion dates, ensuring a clear timeline for the project.

2. Parties Involved

The contract identifies both the client (property owner) and the roofing contractor or company. Contact information for each party, including names, addresses, phone numbers, and any relevant licensing details, is included to prevent misunderstandings and maintain accountability throughout the project.

3. Terms and Conditions

Roofing contracts outline payment terms, pricing structures, and schedules, including deposits, installment payments, and final payments. They may also specify warranty details for materials and workmanship, insurance requirements, safety protocols, and dispute resolution procedures in the event of disagreements.

4. Duration and Renewal

The contract specifies the start and end dates for the project, accounting for potential delays due to weather or unforeseen circumstances. While roofing contracts are often project-specific, they may include provisions for ongoing maintenance agreements or future inspections if requested by the client.

5. Service Specifications

Detailed service specifications ensure both parties agree on the quality and standards of materials and workmanship. These may include the brand and type of roofing materials, color selections, installation methods, and cleanup expectations once the job is complete.

6. Legal Compliance

Roofing contracts must comply with state and local regulations, including building codes, safety standards, and licensing requirements. They may also reference necessary permits or inspections required before, during, or after the roofing work is completed.

7. Confidentiality and Privacy

While less common in roofing contracts, confidentiality clauses may be included if sensitive client information or property details are shared. These provisions ensure both parties respect privacy throughout the project.

Conclusion

A roofing contract provides clarity, accountability, and legal protection for both the property owner and the roofing contractor. By defining the scope of work, payment terms, responsibilities, and legal requirements, it helps prevent disputes and ensures a smooth, professional working relationship. Whether you're hiring a roofer or providing roofing services, understanding the key elements of a roofing contract is essential for a successful and stress-free project.